ADVERTISEMENT FOR BIDS

Bids for the design of the new joint

Crosby Rural Fire Protection District

and Divide County Ambulance Dis-

trict Fire and EMS Hall:

The work will include designing a

new Fire and EMS Hall located

within the city limits of Crosby, North

Dakota.

Bids must be received no later than

5 p.m., April 1, 2021. Mailed bids

must be sent to Crosby Rural Fire

Proctection District Architect Bids,

P.O.Box 84, Crosby, ND, 58730.

1. The bids will be opened at the

Crosby Rural Fire Protection District

above the Crosby City Hall on April

1, 2021 at 7:00 p.m.

2. That each bid must be accompa-

nied by a separate envelope con-

taining the contractor’s license and

bid security. The bid security must

be in a sum equal to five percent of

the full amount of the bid and must

be in the form of a bidder’s bond. A

bidder’s bond must be executed by

the bidder as principal and by a

surety, conditioned that if the

principal’s bid is accepted and the

contract awarded to the principal,

the principal, within ten days after

notice of the award, shall execute a

contract in accordance with the

terms of the bid and the bid bond

and any condition of the governing

body. A countersignature of a bid

bond is not required under this sec-

tion. If a successful bidder does not

execute a contract within the ten

days allowed, the bidder’s bond

must be forfeited to the governing

body and the project awarded to the

next lowest responsible bidder.

3. That a bidder, except a bidder on

a municipal, rural, and industrial wa-

ter supply project using funds pro-

vided under Public Law No. 99-294

[100 Stat. 426; 43 U.S.C. 390a],

must be licensed for the full amount

of the bid as required by section

43-07-12. For projects using funds

provided under Public Law No.

99-294 [100 Stat. 426; 43 U.S.C.

390a], the advertisement must state

that, unless a bidder obtains a

contractor’s license for the full

amount of its bid within twenty days

after it is determined the bidder is

the lowest responsible bidder, the

bid must be rejected and the con-

tract awarded to the next lowest

responsible bidder

4. That no bid may be read or con-

sidered if the bid does not fully com-

ply with the requirements of section

48-01.2 of the North Dakota Century

Code and that any deficient bid sub-

mitted must be resealed and re-

turned to the bidder immediately.

5. That the governing body reserves

the right to reject any and all bids

and rebid the project until a satis-

factory bid is received.

6. This project is a time sensitive

project and therefore will require a

projected completion date. The

Crosby Rural Fire Protection District

would like this project to be complet-

ed by November 30, 2021.

7.The bidder will also be required to

provide proof of insurance.

(March 19-20-22-23-24-25-26-

27-29-30-31; April 1, 2021)

ADVERTISEMENT FOR BIDS

North Dakota Department of

Transportation

Minot District Office HVAC

Improvements

1305 Highway 2 Bypass East

Minot, North Dakota 58701

Sealed Bids will be received for

NDDOT Minot District Office

HVAC Improvements until 2:00

PM local time March 30, 2021, in-

cluding all portions of Work for com-

plete construction as identified in the

Construction Documents and shall

be bid as Separate Prime Sealed

Bids for General, Mechanical, and

Electrical Construction OR One

Sealed Bid for Single Prime Con-

struction. Bids shall be addressed

and delivered to the office of:

Korby R. Seward, District

Engineer

North Dakota Department of

Transportation

Minot District Office

1305 Highway 2 Bypass East

Minot, ND 58701

At that time and place the bids will

be publicly opened and read aloud.

Proposals received after that time

will not be accepted.

The Construction Documents will be

on file and may be examined at the

Office of Ackerman-Estvold, Minot,

North Dakota and the following

Builders Exchanges: Bismarck-

Mandan, Construction Plans Ex-

change, Dickinson, Fargo, Grand

Forks, Minot, Williston, North Dako-

ta; Minnesota Builders Exchange;

Construction Industry Center, and

Sioux Falls Builders Exchange,

South Dakota.

Bidders may obtain Plans and

Specifications by contacting Sonya

Boykin at Ackerman-Estvold by

phone at 701-837-8737 or by email

at sonya.boykin@ackerman-estvold.

com and requesting a link to a

SharePoint folder containing the pro-

ject documents.

All prime contractors obtaining

plans, whether through exchanges

or directly, should direct

Ackerman-Estvold to place them on

the plan holders list.

A pre-bid conference will be con-

ducted on 2:00 PM local time

March 17, 2021 at project site.

Each Bid must be accompanied by a

separate envelope, (attached to the

Bid Envelope) containing a Bid Bond

equal to five percent (5%) of the

amount of the Bid naming North

Dakota Department of Transporta-

tion as Obligee. The Contractor

shall also enclose within the Bid

Bond Envelope a copy of the

Bidder’s North Dakota Contractor’s

License or a copy of their latest

Renewal Certificate issued by the

Secretary of State as per North

Dakota Century Code 43-07-12. All

Contractors who submit Bids must

hold a North Dakota Contractors

License in the highest amount of

their Bids and such license must

have been in effect at least ten (10)

days prior to the date of the Bid

Opening. Any Bid not containing

these documents shall not be ac-

ceptable and shall be returned to the

Bidder unopened. See AIA Docu-

ment A701 “Instructions to Bidders”

in the Project Manual for further in-

formation.

The Owner reserves the right to re-

ject any or all bids and to waive any

informalities in bidding.

The successful bidder will be re-

quired to furnish a Payment Bond,

Performance Bond, Insurance Cov-

erages and other requirements

stipulated in the Project Manual.

No Bidder may withdraw his Bid

within 30 days of the actual date of

the opening.

Korby R. Seward, District Engineer

North Dakota Department of Tran-

sportation

(March 8-15-22, 2021)

FOR YOUR INFORMATION

City of Minot

The City of Minot Board of Equaliza-

tion will meet on Tuesday, April 13,

at 5:30 p.m. in the City Council

Chambers of Minot City Hall (second

floor – 515 2nd Avenue SW).

Questions concerning this meeting

should be directed to the City Asses-

sor’s Office, from 8:00 a.m. to 4:30

p.m., at 701-857-4160.

Kelly Matalka

City Clerk

(March 22-29, 2021)

INVITATION NO: IFB 21-02

GENERAL CONSTRUCTION

IFB 21-03 ELECTRICAL

CONSTRUCTION

IFB 21-04 TOTAL COMBINED

CONSTRUCTION

INVITATION TO BID

BUILDING REMODEL

Bldgs. 2280-90 and 5220-30

Camp Gilbert C. Grafton

Devils Lake, North Dakota

Sealed bids for Building Remodel,

Bldgs. 2280-90 and 5220-30, Camp

Gilbert C. Grafton, Devils Lake,

North Dakota will be received by the

Adjutant General of the State of

North Dakota at Fraine Barracks,

Building 30, Bismarck, North Dako-

ta, until 2:00 PM, April 15, 2021, and

will be publicly read that date and

hour in the location designated. All

bids received after the scheduled

opening time will be returned to the

bidders unopened. The deadline for

receipt of technical questions is no

later than April 8, 2021.

Electronic bidding documents may

be requested. Emails must be ac-

companied by a copy of your current

North Dakota Contractor’s License

or Certificate of Renewal and your

request must be written on business

letterhead. No requests will be ack-

nowledged without receipt of both

documents. Submit request to

ng.nd.ndarng.list.dfe-contract-mana

gement@mail.mil.

Due to COVID 19, the bid opening

will not be open to the public. The

front gate entrance to Fraine Bar-

racks is closed to the general public.

A representative from the Facilities

Engineering Division will be at the

gate from 12:00 p.m. until 1:30 p.m.

CST on April 15, 2021. Bidders may

hand deliver their bids during that

time only. Delivery by courier service

or U.S. Mail are the preferred

methods for delivery.

Modifications to bids are allowed in

accordance with the instructions in

AGND Document 411, Subpara-

graph 4.4.2. Bid modifications must

be received no later than 2:00 p.m.

CST. Be advised, the receipt of

emails and faxed transmissions

have a delay time due to data secu-

rity restrictions and military firewalls.

Allow adequate time for emailed and

faxed transmissions to travel

through our security system. The

OWNER is not responsible for bid

modifications that arrive later than

2:00 p.m. CST on the day of the bid

opening. Emailed bid modifications

must be submitted to:

ng.nd.ndarng.list.dfe-contract-mana

gement@mail.mil.

To listen to the bid opening, you

may dial in:

701-333-2840

ID No. 32089#

Pin No. 32089#

Bidders may submit separate bids

for General Construction work (IFB

21-02) and/or Electrical Construction

work (IFB 21-03). In addition, the Of-

fice of the Adjutant General will al-

low the submission of a Total Com-

bined Construction Bid (single

prime) for the complete project (IFB

21-04). In compliance with NDCC

48-01.2-06, the combined bid (from

a single prime) will not be accepted

unless that bid is lower than the

combined total of the lowest respon-

sible, multiple bids for the project.

IMPORTANT: Davis-Bacon Wage

Rates are required for this project.

OWNER

Office of the Adjutant General

Contract Management Branch

P.O. Box 5511

Bismarck, North Dakota 58506-5511

Telephone: (701) 333-2068

Copies of the bidding documents are

on file at the Construction Plans Ex-

change in Bismarck; Builders Ex-

changes in Dickinson, Fargo, Grand

Forks, Mandan, Minot, Rapid City,

Impact Procurement Technical As-

sistance Center in Fargo, North

Dakota and Minnesota Builders Ex-

change in Minneapolis, Minnesota.

Each bid shall be submitted in dupli-

cate using the bid response forms

provided by the Owner, enclosed in

a sealed opaque envelope and la-

beled with the necessary information

as required by the Supplementary

Instructions to Bidders.

Each bid shall be accompanied by a

separate sealed opaque envelope

containing a bidder’s bond made

payable to The Adjutant General,

State of North Dakota, and executed

by the bidder as principle and by a

surety company authorized to con-

duct business in North Dakota, in a

sum equal to five percent (5%) of

the bidder’s highest total bid combi-

nation, including all add alternates to

the bid items; conditioned that if the

bid is accepted and the contract

awarded, the bidder within ten (10)

days after notice of such award, will

effect and execute a contract in ac-

cordance with the terms of his bid

and provide payment and perfor-

mance bonds as required by law

and the regulations and determina-

tions of the Owner. AIA Document

A310, Bid Bond, is provided in the

electronic project manual and should

be used to execute the bid guaran-

tee.

In compliance with Section 43-07-12

of the North Dakota Century Code,

each contractor submitting a bid

must have a copy of their North

Dakota Contractor’s License or certi-

ficate of renewal issued by the

Secretary of State enclosed in the

bid bond envelope; must be licensed

for the highest amount of their total

bid combination including add alter-

nates; and such license must have

been in effect at least ten (10) days

prior to the date of the bid opening.

No bid will be read or considered

which does not fully comply with the

provisions herein as to bid bond and

contractor license, and any deficient

bid submitted will be resealed and

returned to the bidder immediately.

The Owner reserves the right to hold

all legitimate bids for a period of

forty-five (45) days following the date

fixed for the bid opening. It is the in-

tent of the Owner to award a con-

tract to the lowest and best bidder.

The Owner further reserves the right

to reject any and all bids and to

waive irregularities, and shall incur

no legal liability for the State for the

payment of any monies until the

contract is awarded and approved

by the proper authorities.

In compliance with Section

48-01.2-10 of the North Dakota Cen-

tury Code, the successful bidder

shall be required to furnish payment

and performance bonds covering the

faithful performance of the Contract

and the payment of all obligations

thereunder, and all additional obliga-

tions required by the laws of the

State of North Dakota. Each bond

shall be in an amount equal to the

full contract sum.

DATED: 22 March 2021

OFFICE OF THE ADJUTANT GEN-

ERAL

Bismarck, North Dakota

By: /s/ JACKIE A. HUBER

Brigadier General, NDNG

Deputy Adjutant General

Contracting Officer

(March 22-29; April 5, 2021)

NOTICE

Burlington Planning Commission will

hold a public hearing Mar. 30, 2021

at 5:00pm at Burlington City Hall,

225 N Wallace Street. The following

public hearings will be opened:

Joshua M Nelson of 306 3rd Ave E

Burlington, ND, located inside

Burlington’s city limits.applied for a

Conditional Use permit to allow him

to sell firearms to himself, family and

close friends. Gaylin Schmidt- com-

bining outlots 71, 72 & 73 of Section

12, Township 155 N, Range 84 W,

Ward Co ND, not in Burlington City

limits. Dividing lots for Mark & Debra

Skees- Outlot 41, being a portion of

Outlot 36, Section 1, Township 155

N, Range 84 W, located inside

Burlington’s city limits. Jerry & Mary

Neuhafen- Outlot 42, being a portion

of Outlot 6, Section 1, Township 155

N, Range 84 W, located inside

Burlington’s city limits. Jason &

Nicole Schnaible- Outlot 43, being a

portion of Outlot 17, Section 1,

Township 155 N, Range 84 W, lo-

cated inside Burlington’s city limits.

The Planning Commission’s recom-

mendation will be reviewed by the

Burlington City Council at the regular

city council meeting April 5, 2021 at

7:00pm, also at the City Hall, 225 N

Wallace Street.

Mary Lynn Brooks, Auditor

(March 15-22, 2021)

NOTICE OF HEARING PETITION

FOR FORMAL PROBATE OF

WILL AND APPOINTMENT OF

PERSONAL REPRESENTATIVE

Probate No. 51-2021-PR-51

IN THE DISTRICT COURT,

STATE OF NORTH DAKOTA,

COUNTY OF WARD, NORTH

CENTRAL JUDICIAL DISTRICT

In the Matter of the Estate of

Mary E. Frunz, Deceased.

NOTICE IS HEREBY GIVEN that

Gayle D. Frunz has filed herein a

Petition for Formal Probate of Will

and Appointment of a Personal

Representative of the Estate of Mary

E. Frunz, deceased.

A hearing has been set upon said

petition on the 19th day of April,

2021, at 9:15 a.m., at the Courtroom

of the above-named Court in the

City of Minot, County of Ward, State

of North Dakota.

Dated this 4th day of March, 2021.

/s/ Brian W. Hankla

Brian W. Hankla (ID #04728)

McGEE, HANKLA & BACKES, P.C.

2400 Burdick Expy. E., Suite 100

P.O. Box 998

Minot, ND 58702-0998

ATTORNEYS FOR THE PETITION-

ER

(March 8-15-22, 2021)

NOTICE OF REAL ESTATE SALE

CIVIL NUMBER: 51-2019-CV-00638

IN THE STATE OF NORTH

DAKOTA, COUNTY OF WARD

IN THE DISTRICT COURT, NORTH

CENTRAL JUDICIAL DISTRICT

Wells Fargo Bank, N.A.

Plaintiff,

v.

Amy N. Reiter; Affinity First Federal

Credit Union; Credit Collections

Bureau; ProCollect Services LLC;

The United States of America acting

by and through the Secretary of

Housing and Urban Development;

Unifund CCR, LLC; any person in

possession, and all persons unk-

nown, claiming any estate or interest

in, or lien or encumbrance upon, the

real estate described in the com-

plaint,

Defendants.

1. Judgment in the amount of

$154,752.35, having been entered in

favor of Plaintiff and against Defen-

dants, which Judgment was filed

with the Clerk of Courts of Ward

County, North Dakota, on November

15, 2019, for the foreclosure of a

real estate mortgage.

2. Notice is hereby given pursuant to

said Judgment that the real property

described as:

Lot 1, Leier Second Addition to the

City of Minot, Ward County, North

Dakota.

Real Property address: 1111 78th

Street Southeast, Minot, ND 58701

The above real property is the sub-

ject of the Mortgage dated March

20, 2009, which Mortgagor, Amy N.

Reiter, executed and delivered to

Mortgage Electronic Registration

Systems, Inc., as Mortgagee, as

Nominee for Kirkwood Bank & Trust

CO., its successors and assigns,

and recorded in the office of the

Clerk and Recorder of Ward County,

North Dakota, on March 30, 2009,

Instrument Number 2895265, which

is subject to the entered Judgment.

Said Mortgage was assigned to

Plaintiff, its successors or assigns,

by Assignment of Mortgage record-

ed May 5, 2014, Instrument Number

2972631.

3. In order to realize the amount of

$154,752.35, as of November 15,

2019, plus interest accruing

thereafter on said amount at the rate

of 3.75% per year together with the

costs and expenses of sale, the pro-

perty will be sold subject to redemp-

tion as provided by law as one par-

cel of land at public auction, subject

to any lien for unpaid real estate

taxes and assessments of Ward

County, North Dakota, and ease-

ments and restrictions of record, to

the highest bidder for cash under the

direction of the Sheriff of Ward

County, North Dakota, at the main

entrance of the Ward County Court-

house located at 315 SE 3rd Street,

Minot, North Dakota 58701, on May

5, 2021 (“Sale Date”), at 10:00 AM.

4. If the sale is set aside for reason,

the Purchaser at the sale shall be

entitled only to a return of the depo-

sit paid. The purchaser shall have

no further recourse against the Mort-

gagor, the Mortgagee or the

Mortgagee’s attorney.

DATED this 17th day of March,

2021.

For: Robert Roed

/s/Jamie Williams

Deputy Sheriff of Ward County

Halliday, Watkins & Mann, P.C.

/s/ Scott S. Skeen

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

801-355-2886

Email: scott@hwmlawfirm.com

ND Bar No.: 09334

(March 22-29; April 5, 2021)

NOTICE TO CREDITORS

Case No. 51-2021-PR-00038

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of

Ethel Mae Pagett, a/k/a Ethel M.

Pagett, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

personal representative of the above

estate. All persons having claims

against the said deceased are re-

quired to present their claims within

three (3) months after the date of the

first publication or mailing of this no-

tice or said claims will be forever

barred. Claims must either be

presented to Barbara J. Olson, per-

sonal representative of the

above-named estate, in care of

Louser & Zent, P.C., Town & Coun-

try Center, 1015 South Broadway,

Suite 15, Minot, North Dakota

58701, or filed with the Court.

Dated this 2nd day of March, 2021.

/s/Barbara J. Olson

Barbara J. Olson

6724 County Road 15 W.

Minot, ND 58703

Diane R. Louser (ID #03882)

LOUSER & ZENT, P.C.

Town & Country Center

1015 South Broadway – Suite 15

Minot, ND 58701

Telephone No. (701) 837-4846

Attorneys for the Personal

Representative

(March 8-15-22, 2021)

NOTICE TO CREDITORS

Case No. 51-2021-PR-00028

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the matter of the Estate of Lane

B. Sundsbak, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned have been appoint-

ed Co-Personal Representatives of

the above estate. All persons hav-

ing claims against the said de-

ceased are required to present their

claims within three (3) months after

the date of first publication or mailing

of this notice or said claims will be

forever barred. Claims must be

presented to Kelly M. Sundsbak and

Larry J. Sundsbak, Co-Personal

Representatives, in care of Miller

Law Office, P.C., Northland Profes-

sional Building, 600 22nd Ave. NW,

Suite B3, Minot, North Dakota

58703, or filed with the Court.

Dated this 26th day of February,

2021.

/s/Kelly M. Sundsbak

Kelly M. Sundsbak

Co-Personal Representative

/s/Larry J. Sundsbak

Larry J. Sundsbak

Co-Personal Representative

Marie A. Miller (ID06617)

MILLER LAW OFFICE, P.C.

Northland Professional Building

600 22nd Ave. NW, Suite B3

Minot, ND 58703

(701)838-2770

E-serve:

millerlawofficeminot@gmail.com

Attorney for the Co-Personal

Representatives

(March 15-22-29, 2021)

NOTICE TO CREDITORS

Case No. 51-2021-PR-00029

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the matter of the Estate of Leah

F. Sundsbak, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned have been appoint-

ed Co-Personal Representatives of

the above estate. All persons hav-

ing claims against the said de-

ceased are required to present their

claims within three (3) months after

the date of first publication or mailing

of this notice or said claims will be

forever barred. Claims must be

presented to Kelly M. Sundsbak and

Larry J. Sundsbak, Co-Personal

Representatives, in care of Miller

Law Office, P.C., Northland Profes-

sional Building, 600 22nd Ave. NW,

Suite B3, Minot, North Dakota

58703, or filed with the Court.

Dated this 26th day of February,

2021.

/s/Kelly M. Sundsbak

Kelly M. Sundsbak

Co-Personal Representative

/s/Larry J. Sundsbak

Larry J. Sundsbak

Co-Personal Representative

Marie A. Miller (ID06617)

MILLER LAW OFFICE, P.C.

Northland Professional Building

600 22nd Ave. NW, Suite B3

Minot, ND 58703

(701)838-2770

E-serve:

millerlawofficeminot@gmail.com

Attorney for the Co-Personal

Representatives

(March 15-22-29, 2021)

NOTICE TO CREDITORS

Probate No. 51-2021-PR-00050

IN THE DISTRICT COURT OF

WARD COUNTY, STATE OF

NORTH DAKOTA

In the Matter of the Estate of Ted

Wiese Handeland, Deceased.

NOTICE IS HEREBY GIVEN that

the undersigned has been appointed

personal representative of the above

estate. All persons having claims

against the deceased are required to

present their claims within three

months after the date of the first

publication or mailing of this notice

or the claims will be forever barred.

Claims must either be presented to

Katherine W. Bonebrake, personal

representative of the estate, at 1082

Lake Loop Rd., Bottineau, ND

58318 or filed with the Court.

Dated this 18th day of March, 2021.

/s/Katherine W. Bonebrake

1082 Lake Loop Rd.

Bottineau, ND 58318

(March 22-29; April 5, 2021)

SUMMONS

Civil No. 51-2021-CV-00361

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

ProCollect Services, LLC,

Plaintiff,

vs.

Samantha Metcalf,

Defendant.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANT:

YOU ARE HEREBY SUMMONED

and required to appear and defend

against the Complaint in this action,

which is herewith served upon you,

by serving on the undersigned an

Answer or other proper response

within twenty-one days after service

of this Summons upon you, ex-

clusive of the day of service. If you

fail to do so, judgment by default will

be taken against you for the relief

demanded in the complaint.

Dated March 4, 2021.

/s/Christopher A. Carlson

Chistopher A. Carlson (ID #03378)

PO Box 1097

Bismarck, North Dakota 58502-1097

701-258-4800

carlsonlaw@qwestoffice.net

Attorney for the Plaintiff

(March 8-15-22, 2021)

SUMMONS

Civil No. 51-2021-CV-00362

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

ProCollect Services, LLC,

Plaintiff,

vs.

Jessie and Betsy Casey,

Defendant.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANT:

YOU ARE HEREBY SUMMONED

and required to appear and defend

against the Complaint in this action,

which is herewith served upon you,

by serving on the undersigned an

Answer or other proper response

within twenty-one days after service

of this Summons upon you, ex-

clusive of the day of service. If you

fail to do so, judgment by default will

be taken against you for the relief

demanded in the complaint.

Dated March 4, 2021.

/s/Christopher A. Carlson

Chistopher A. Carlson (ID #03378)

PO Box 1097

Bismarck, North Dakota 58502-1097

701-258-4800

carlsonlaw@qwestoffice.net

Attorney for the Plaintiff

(March 8-15-22, 2021)

SUMMONS

51-2021-DM-00111

STATE OF NORTH DAKOTA,

COUNTY OF WARD, IN DISTRICT

COURT, NORTH CENTRAL

JUDICIAL DISTRICT

Jeremy J. Davison,

Plaintiff,

vs.

Shauna R. Davison,

Defendant.

THE STATE OF NORTH DAKOTA

TO THE ABOVE-NAMED DEFEN-

DANT:

You are hereby summoned and re-

quired to appear and defend against

the Complaint in this action which

has been filed with the Ward County

Clerk of District Court, Minot, North

Dakota, and to serve a copy of your

answer or other proper response

upon the undersigned attorney

within twenty-one (21) days after the

completion of service of this Sum-

mons upon you. Service is complete

upon the expiration of fifteen (15)

days after the date of the first publi-

cation. If you fail to appear or

answer, judgment by default will be

taken against you for the relief

demanded in the Complaint.

Dated at Minot, North Dakota, this

2nd day of March, 2021.

THOMAS LAW FIRM

/s/Robert S. Thomas ID #04421

Attorney for Plaintiff

114 S. Main Street

P.O. Box 2298

Minot, North Dakota 58702

(701)852-1602

thomaslawyers@gmail.com

(March 8-15-22, 2021)